Services
Mayan3 Creations Pvt. Ltd. offers residential and commercial interior design solutions, including turnkey execution and retrofitting. Services are provided based on mutually agreed proposals, timelines, and budgets. All services are subject to a written agreement or contract.
Consultations and Proposals
Initial consultations may be offered free or at a nominal fee, as specified. Design proposals and quotes provided are based on preliminary information and may be revised following site visits or detailed assessments.
Client Responsibilities
Clients are responsible for providing accurate information and timely decisions to avoid delays. Any changes to the scope of work after confirmation may incur additional costs and time extensions.
Payments
All payments must be made as per the agreed project milestones and payment schedule. Late payments may attract interest or lead to suspension of services. We reserve the right to revise our pricing without prior notice for new projects or phases.
Project Timelines
While we strive to adhere to agreed timelines, delays due to unforeseen circumstances such as client approvals, material shortages, or external factors (e.g., labor strikes, force majeure) may occur. We will communicate delays as they arise.
Intellectual Property
All design concepts, drawings, plans, and documents shared by MayanSpaces Pvt. Ltd. remain our intellectual property unless otherwise agreed in writing. Reproduction or distribution without permission is prohibited.
Limitation of Liability
MayanSpaces Pvt. Ltd. is not liable for any indirect, incidental, or consequential damages resulting from use of our website or services. Liability for direct damages is limited to the value of the services provided.
Third-Party Services and Products
We may recommend third-party vendors or products. While we vet our partners carefully, we are not responsible for their performance, warranties, or service quality unless explicitly stated in the contract.
Website Use
You agree not to misuse our website, post false information, or attempt unauthorized access. We reserve the right to suspend access for violation of these terms.
Privacy
Your privacy is important to us. Please refer to our Privacy Policy for information on how we collect, use, and protect your personal data.
Changes to Terms
We reserve the right to update these Terms at any time. Continued use of our website or services constitutes acceptance of the updated Terms.
Governing Law
These Terms are governed by the laws of India. Any disputes will be subject to the exclusive jurisdiction of the courts located in Bengaluru, India.